Construction Dispute

Subscribe to Construction Dispute via RSS

N. Plains Res. Council v. United States Army Corps of Eng’rs, No. 4:19-cv-00044-BMM, 2020 BL 35412 (9th Cir. May 14, 2020)

Oil and gas pipeline construction may no longer proceed under Nationwide Water Permit 12 (NWP 12). The Ninth Circuit, by way of a two-judge panel, denied challenges to a district court decision vacating NWP 12 and enjoining the United States Army Corps (Army Corps) from authorizing oil and gas pipeline construction projects pursuant to NWP 12. The Order, which was issued without an opinion, has national effect and set a briefing schedule for reconsideration of a motion for an administrative stay. N. Plains Res. Council v. United States Army Corps of Eng’rs, No. 4:19-cv-00044-BMM.

Days after the World Health Organization declared the COVID-19 outbreak a global pandemic, governments from around the world scrambled to enact measures aimed at mitigating the spread of the virus. In the United States, cities and states have enacted travel restrictions, issued shelter-in-place orders, and directed nonessential businesses to shutter. While all aimed at mitigating the spread of the virus, these measures will have an immense disruptive impact on businesses and industries around the world — the construction sector included.

As notices concerning force majeure, changes in law, and change orders swirl, parties should prepare themselves for how these disputes will be managed and resolved. The COVID-19 outbreak will rapidly reshape how the construction sector does business. This article offers our insight into just once facet of the construction industry: alternative dispute resolution and how the COVID-19 outbreak has and will affect construction disputes going forward.

Much has been written about whether and how COVID-19 qualifies as a force majeure event, and some additional information can be found here. But typical force majeure provisions entitle contractors to only schedule relief. While force majeure clauses may limit exposure to liquidated or consequential damages for delays, contractors who incur increased costs resulting from COVID-19 related delays should carefully evaluate the entirety of their contractual rights to not only an extension of time, but also recover prolongation costs. To assist in this endeavor, this article looks beyond force majeure to other potentially relevant contractual provisions. Potential remedies under the various contractual clauses discussed below will depend on the specific contractual language and project-specific facts.

With the signing of the United Nations Convention on International Settlement Agreements Resulting from Mediation in August 2019, there has been a newfound focus on how parties can improve and expand the use of alternative forms of dispute resolution outside conventional litigation and arbitration proceedings.  Pepper Hamilton attorneys Albert Bates…

This article was originally published on December 3, 2019 on ConsensusDocs. It is reprinted here with permission.

Construction contracts often include a “no damage for delay” clause that denies a contractor the right to recover delay-related costs and limits the contractor’s remedy to an extension of time for noncontractor-caused delays to a project’s completion date. Depending on the nature of the delay and the jurisdiction where the project is located, the contractual prohibition against delay damages may well be enforceable. This article will explore whether an enforceable no-damage-for-delay clause is also a bar to recovery of “acceleration” damages, i.e., the costs incurred by the contractor in its attempt to overcome delays to the project’s completion date.

Chinese Hosp. Ass’n v. Jacobs Eng’g Grp., Inc., 2019 BL 330340, 2 (N.D. Cal. Sept. 03, 2019)

This case arises out of the alleged breach of contract and defective design for the construction of a new hospital in San Francisco.  During construction, property owner and plaintiff Chinese Hospital Association (“Chinese Hospital”) became aware of alleged defects involving the designs provided by its subcontractor, architect-defendant Jacobs Engineering Group, Inc. (“Jacobs”).  Chinese Hospital terminated its contract with Jacobs for convenience mid-construction.

Skanska USA Building, Inc. v. J.D. Long Masonry, Inc., No. 1:16-cv-00933, 2019 BL 336852, (D. Md. Sept. 9, 2019)

On September 9, 2019, a Maryland federal court awarded Skanska USA Building, Inc. (“Skanska”) compensatory damages, pre- and post-judgment interest, and litigation expenses including attorney and expert fees in its suit against subcontractor J.D. Long Masonry, Inc. (“Long”) for defective masonry work at a Johns Hopkins University research facility.

  1. Lost profits, not part of unpaid contract balance, may be recoverable as consequential damages in contract claim, but cannot be included in lien. TSP Services Inc. v. National-Standard, LLC, 2019 BL 340267 (Mich. Ct. App. Sept. 10, 2019)

National-Standard, LLC contracted TSP Services, Inc. for asbestos abatement, demolition, restoration,…

Precision Hydraulic Cylinders, Inc. v. Manufacturing. Technology, Inc., No. 7:18-CV-203-FL, 2019 BL 344743, 2019 U.S. Dist. LEXIS 156670 (E.D.N.C. Sept. 13, 2019)

Precision Hydraulic Cylinders, Inc. (“Precision”) issued a series of purchase orders to Manufacturing Technology, Inc. (“MTI”) to weld steel components together to create hydraulic cylinders. MTI agreed to develop welds for Precision’s small and large cylinders under two separate purchase orders.

United Illuminating Company v. Whiting-Turner Contracting Co. v. Cherry Hill Construction Co., Inc., et al. v. GEI Consultants, Inc., et al., 3:18-cv-00327-WWE (D. Conn. 2019)

In 2010 The United Illuminating Company (“UI”), an electric utility company, and Whiting-Turner, a construction contractor, entered into a general contractor agreement for the construction of the United Illuminating Central Facility Project (the “Project”) in Orange, Connecticut.  The Project required construction of an office building, an operations building, and related parking lots and common driveways.  Whiting-Turner and Cherry Hill Construction Co. (“Cherry Hill”), a heavy civil construction contractor, then entered into a subcontractor agreement which required Cherry Hill to perform site work.