Contracts

Subscribe to Contracts via RSS

Precision Hydraulic Cylinders, Inc. v. Manufacturing. Technology, Inc., No. 7:18-CV-203-FL, 2019 BL 344743, 2019 U.S. Dist. LEXIS 156670 (E.D.N.C. Sept. 13, 2019)

Precision Hydraulic Cylinders, Inc. (“Precision”) issued a series of purchase orders to Manufacturing Technology, Inc. (“MTI”) to weld steel components together to create hydraulic cylinders. MTI agreed to develop welds for Precision’s small and large cylinders under two separate purchase orders.

MBlock Investors, LLC v. Bovis Lend Lease, Inc., etc., et al., 44 Fla. L. Weekly d1432 (3d DCA 2019)

A Florida Appellate Court recently reversed a trial court’s decision granting summary judgment finding an issue of fact based upon an expert affidavit.  The underlying matter involved an action by MBlock Investors against Lend Lease (US) Construction, Inc. for latent defects following MBlock’s acquisition of a property commonly known as the Midblock Miami East Project (the “Property”).

Rad and D’Aprile, Inc. v. Arnell Construction Corp, No. 502464/14, 2019 BL 131606 (NY. Sup. Ct. April 3, 2019)

In June of 2001, Arnell Construction Corp. (“Arnell”) entered into a prime contract to build two sanitation garages in Brooklyn for the New York City Department of Sanitation (the “City”).  Arnell subcontracted the project’s masonry work to Rad and D’Aprile, Inc. (“Rad”).  After execution of the subcontract, Rad was informed that the start of work would be delayed because the City had not yet obtained ownership or access to all portions of the site.  When its work did commence, only limited portions of the site were available.  This caused inefficiencies in Rad’s work and caused it to incur increased costs.

Aquatherm, LLC v. CentiMark Corp, 2019 BL 13240 (D. Utah Apr. 12, 2019)

Stag II Lindon LLC and Stag Industrial Inc. (collectively “Stag”) owned a building in Lindon, Utah.  Stag contracted with CentiMark Corp. (“CentiMark”) to perform work on the building’s roof.  CentiMark’s work required it to manipulate, move, and reinstall existing heating cables on the roof.  Shortly after completion of the work, in March of 2014, a fire occurred on the roof which was traced to the location of heat tape, which CentiMark had removed and replaced.

Westfield Ins. Co. v. Weaver Cooke Constr., LLC, 2019 BL 129431 (E.D.N.C. Apr. 11, 2019)

This case arises out of the alleged defective construction of a condominium complex in North Carolina.  In 2009, the developer on the project filed suit for the alleged construction defects.  This related coverage lawsuit then ensued between the parties’ insurers regarding a duty to defend the general contractor.

A.E. Rosen Elec. Co. v. Plank, LLC, No. 07862-7, 2019 BL 113951 (Sup. Ct. Mar. 01, 2019)

On March 1, 2019, the Supreme Court of New York, Albany County, granted a subcontractor’s motion for summary judgment on a payment dispute involving a “pay-when-paid” contract provision.

Defendant Plank, LLC (“Contractor”) entered into a construction contract with Dutch Village, LLC (“Owner”) to act as the general contractor for the construction of four apartment buildings (“Project”).  Thereafter, Contractor entered into a subcontract with Plaintiff A.E. Rosen Electrical, Inc. (“Subcontractor”) for electrical work on the Project.  After nine months of work on the Project, a payment dispute arose between the Owner and Contractor.  At that time, Contractor directed the Subcontractor to cease work on the Project.

Whiting-Turner Contracting Co. v Guar. Co. of N. Am. USA, 2019 BL 97923 (Colo. App. Mar. 21, 2019).

This construction dispute involved rights and obligations under a performance bond supplied for an office building construction project in Denver, Colorado.  Whiting-Turner Contracting Company was the general contractor, and it subcontracted Klempco Construction to construct an anchor system for the project’s underground parking garage.  Klempco provided performance and payment bonds for the project from Guarantee Company of North America USA (“GCNA”).  When Klempco fell behind schedule, it stopped paying its sub-subcontractors and directed Whiting-Turner to assume responsibility for its work and sub-subcontractors.

SMJ Gen. Constr., Inc. v. Jet Commer. Constr., LLC, No. S-16785/16985, 2019 BL 131640 (Alaska Apr. 12, 2019)

In 2016, Jet Commercial Construction, LLC (“Jet”) entered into a subcontract with SMJ General Construction, Inc. (“SMJ”) to supply materials and labor for the construction of a restaurant in Hawaii.  The subcontract contained a dispute resolution provision that required the parties to first mediate any dispute and then submit it to arbitration if mediation was unsuccessful.  It also included a choice-of-law and venue provision designating Oklahoma Law and the courts of Cleveland County, Oklahoma for any lawsuits pertaining to the Agreement’s enforcement.

R&O Constr. Co. v. MBA Gen. Contracting, LLC, No. 1:18-cv-00042, 2019 BL 98680 (D. Utah Mar. 21, 2019)

On March 21, 2019, a Utah federal court granted Defendants MBA General Contracting, LLC and Cory Martin’s motion to dismiss R&O Construction Company’s claim for attorney fees.
R&O, as general contractor of a construction project, entered into two subcontracts with MBA to perform concrete work.  The first subcontract, entitled Master Subcontract Agreement, outlined general obligations between the parties.  The second, entitled Work Authorization Document, outlined more specific obligations.  R&O asserted various causes of action against MBA arising from MBA’s alleged breach of the subcontracts, including a claim for attorney fees.  MBA moved to dismiss the attorney fees claim, arguing that neither subcontract provides for such an award.

James Talcott Construction, Inc. v. United States, No. 14-427 C, 2019 BL 72711, at *1 (Fed. Cl. Mar. 4, 2019)

In May of 2010, the United States, acting through the Department of Defense (the “Government”) awarded a contract to James Talcott Construction, Inc. (“Talcott”) to replace existing housing for military families at the Malmstrom Air Force Base in Great Falls, Montana.  Talcott was required to construct thirteen buildings, each comprising seventy housing units.  Each building was to be constructed with concrete foundations and wood framing, and the project’ design called for wooden floor joists and subfloor decking to be enclosed in crawlspaces.  The contract stated that the “structural drawings and specification represent the finished structure… [but] do not indicate the method of construction.  The contractor will provide all measures necessary to protect the structure during construction.”  The plans and specifications were silent as to ventilation of the crawlspaces.