Construction Dispute

Subscribe to Construction Dispute via RSS

Nova Contr., Inc. v. City of Olympia, No. 48644-0-II, 2017 Wash. App. LEXIS 913 (Ct. App. Apr. 18, 2017)

This case arose out of a public project in which the City of Olympia (“City”) hired Nova Contracting, Inc. (“Nova”) to replace a culvert. A prior City project on which Nova completed work ended with Nova receiving extra compensation due to the City’s design errors and, as a result, a grudge held by some City staff against Nova.  The present contract required Nova to send submittals describing its plans for bypass pumping and excavation to the City’s engineer for approval before it could begin work.  The City’s decision regarding submittals was final and Nova bore the risk and cost of delay due to any non-approval.
The City issued its Notice to Proceed on August 11, 2014, but Nova could not begin construction due to the City’s rejection of its submittals. Nearly one month later, the City declared Nova to be in default because it failed to provide satisfactory submittals and failed to mobilize to the site.  Coincidentally, that same day, Nova had mobilized to the site; the City, however, later ordered Nova to cease work because it had commenced operations before obtaining the requisite approval.  Nova protested the City’s declaration of default, but the City terminated the contract on September 24.

Nova filed suit against the City for breach of contract, claiming that its handling of the submittals imposed requirements that were not part of the project’s specifications, thereby delaying Nova’s performance to a point where the project could not be timely completed. In support thereof, Nova’s witnesses declared that the City had appeared to be reviewing the submittals with the goal of rejecting them as a sort of “gotcha” review employed to prevent Nova’s performance.  The City moved for summary judgment, and the trial court granted its motion.  Nova appealed, arguing that there existed genuine issues of fact as to why the project was not completed and that the City had breached its duty of good faith by preventing Nova from attaining its justified contractual expectations.  The City argued that the duty of good faith did not apply because it had unconditional authority to accept or reject Nova’s submittals.

Melchert v. Pro Elec. Contrs., 2017 Wis. Lexis 169 (April 7, 2017)

The Wisconsin Department of Transportation (“DOT”) contracted with Payne & Dolan (“P&D”) as General Contractor on a road improvement project. P&D in turn contracted with Pro Electric Contractors (“Pro Electric”) to install concrete bases for new traffic signal poles.  DOT provided Pro Electric with detailed plans and specifications for the project (“Project Plan”) that specified the location of the concrete bases and the excavation equipment to be used.  Pro Electric was required to comply with the Project Plan and could only make deviations if approved by DOT’s engineer.

While excavating one of the specified locations, Pro Electric unknowingly severed a sewer line, causing sewage backup and flooding on adjoining private property. Pro Electric then backfilled the excavation site without inspecting the sewer line for damage.  The private property owners (“Owners”) brought a negligence action against Pro Electric.  The trial court granted summary judgment in favor of Pro Electric, ruling that it was immune from liability because it was merely implementing DOT’s design decisions.  The court of appeals affirmed, and Owners appealed to the Supreme Court of Wisconsin.

In re: Linear Electric Co., Inc., No. 16-1477, 2017 U.S. App. Lexis 5527 (3d Cir., March 30, 2017)

This case concerns whether suppliers, Cooper Electrical Supply Co. and Samson Electrical Supply Co. (“Suppliers”), could file construction liens under New Jersey law, despite the fact that Linear Electric Inc. (“Contractor”), filed a petition for bankruptcy, which automatically stays any act to create or perfect any lien against the contractor’s property. Two weeks after Contractor filed for bankruptcy, the Suppliers filed construction liens against projects in New Jersey where the materials were incorporated.  Following a motion by the Contractor, the Bankruptcy Court held that the liens were in violation of the automatic stay provision of the Bankruptcy Code. The District Court affirmed the Bankruptcy Court’s holding that, under New Jersey law, the liens were claims against the Contractor’s accounts receivables, which receivables are part of the bankruptcy estate and protected by the automatic stay.  On appeal, the Third Circuit affirmed the ruling of the District Court.

Broomfield Senior Living Owner, LLC v. R.G. Brinkmann Co., 2017 Colo. App. Lexis 261 (March 9, 2017)

R.G. Brinkmann Company, as general contractor, was retained by Sunrise Development, Inc., a major national developer, for the construction of a senior assisted and independent living facility in Broomfield, Colorado. The project was owned by Broomfield Senior Living Owner, LLC.

Section 13.7 of the contract between Brinkmann and Sunrise provided that all claims arising from defects in Brinkmann’s work would be deemed to accrue no later than final completion of the project. On May 15, 2009, the project achieved final completion when a certificate of occupancy was issued.  No defects in the project were noted at that time.  In the Fall of 2012, however, Broomfield discovered broken sewer pipes at the project.  Further investigation revealed a number of defects that Broomfield attributed to Brinkmann’s poor construction.

On July 21, 2014, Broomfield filed a lawsuit asserting various defective workmanship claims against Brinkmann. Brinkmann responded by moving for summary judgment, arguing that under Section 13.7 of its contract with Sunrise, all defective work claims accrued no later than final completion on May 15, 2009 and that Colorado’s two year statute of limitations for civil claims therefore expired on May 15, 2011.  The trial court granted Brinkmann’s motion and dismissed Broomfield’s claims.

Hill County High School District No. A v. Dick Anderson Construction, Inc., 2017 Mont. LEXIS 38 (Mt. Feb 7, 2017)

This action arose out of the design and construction of a new roof for a high school in Hill County, Montana. The roof was built by Dick Anderson Construction, Inc. (“Contractor”) and designed by Springer Group Architects, P.C. (“Architect”). While the parties disputed whether the roof was ever completed to the School District’s satisfaction, the school was in full use by April 1998 and final payment was issued around that same time.

Problems emerged with the roof almost immediately. The Contractor and Architect worked with the School District to address the problems through October 2003 when the Architect informed the School District that repairs were finished and that no further work was necessary. But the roof partially collapsed in 2010 and the School District filed suit the following year.

Hensel Phelps Constr. Co. v. Thompson Masonry Contractor, Inc., et. al., No. 151780, 2016 Va. LEXIS 166 (Va. Nov. 3, 2016)

The dispute arose from the construction of a student health and fitness center at Virginia Tech. The prime contractor, Hensel Phelps, and its subcontractors substantially completed their work in 1998, and Virginia Tech made final payment in 1999. In April 2012, Virginia Tech discovered defects in the work, elected to repair them, and then sought to recover the costs from Hensel Phelps. Despite the significant passage of time between completion of the work and Virginia Tech’s assertion of its claims, Hensel Phelps could not invoke the statute of limitations because under Virginia Code § 8.01-231, statutes of limitation do not apply to claims asserted by Commonwealth agencies such as Virginia Tech.  Ultimately, Hensel Phelps paid $3,000,000 to Virginia Tech to settle the defective work claims.

Hensel Phelps, in turn, sought to recover from the subcontractors that performed the defective work. When the subcontractors refused to pay, Hensel Phelps commenced an action alleging, among other things, breach of contract against the subcontractors and their sureties. All of the defendants argued that Hensel Phelps’ claims were barred by the applicable statute of limitations. The lower courts agreed. On appeal, the Virginia Supreme Court affirmed.

Scott Enters., Inc. v. City of Allentown, 2016 Pa. LEXIS 1503 (Pa. July 19, 2016)

The Supreme Court of Pennsylvania reversed an order of the Commonwealth Court and held that the prompt payment provisions of the Commonwealth Procurement Code, 62 Pa. C.S. §3931-3939 (the “Prompt Payment Act”), do not mandate an award of penalty interest and attorneys’ fees upon a finding that the government withheld payments from the contractor in bad faith.

On June 16, 2016, the U.S. Supreme Court ruled in the matter of Universal Health Services, Inc. v. United States ex rel. Escobar, 136 S. Ct. 1989 (2016), changing the legal landscape for False Claims Act qui tam claims concerning the implied false certification theory of liability. This article will discuss the Escobar holding and examine relevant considerations for contractors in light of this ruling.

Elliott-Lewis Corp. v. Skanksa USA Bldg., Inc., 2016 U.S. Dist. LEXIS 59406 (E.D.Pa. May 4, 2016)

The Federal District Court for the Eastern District of Pennsylvania held that the narrow exception to the economic loss doctrine carved out in Bilt-Rite Contractors, Inc. v. The Architectural Studio – where the Pennsylvania Supreme Court held that architects and other design professionals may be held liable to third parties that rely to their detriment on false information provided in design documents by architects and other design professionals – does not apply to a contractor that supplied information to design professionals in connection with remedial work performed by the contractor.

ITT Water & Wastewater USA, Inc. v. L. D’Agostini & Sons, Inc., 2016 Mich. App. LEXIS 579 (March 17, 2016)

This action arises out of a contract dispute between plaintiff, ITT Water & Wastewater USA, Inc. (“ITT”), and defendant, L. D’Agostini & Sons, Inc./Lakeshore Engineering Services, Inc. Joint Venture (“D’Agostini”), related to ITT’s supply of eight water pumps to D’Agostini on a project to construct a sanitary and storm water treatment and pumping station.  D’Agostini filed a counterclaim against ITT, alleging that ITT’s late pump delivery delayed the project by 103 days.  The trial court granted ITT’s motion for partial summary disposition and ruled that D’Agostini could not rely upon the Eichleay formula for determining its alleged home office overhead damages.  The parties then dismissed, without prejudice, the remaining claims and D’Agostini appealed.