Metric Construction Co., Inc. v. United States
2008 U.S. Claims LEXIS 5 (Fed. Cl., Jan. 7, 2008)
Metric Construction was awarded the contract to construct a warehouse for the United States Army Corps of Engineers at an Air Force base in Utah. After the roof developed serious leaks, the Corps required Metric to replace the roof. Metric then submitted a request for equitable adjustment in the amount of $2,173,091.85 for costs incurred in repairing water damage caused by the leaks, replacing damaged property in the warehouse, and installing a new roof, under the theory that the Corps’ design specifications for the structural steel underlying the roof were defective, and that defective specifications and the Corps’ communications with Metric regarding the roof installation were misrepresentations on which Metric relied to its detriment.

1800 Ocotillo, LLC v. WLB Group, Inc.
2008 Ariz. App. LEXIS 9 (Jan. 29, 2008)
The Court of Appeals of Arizona held that a state statute prohibiting design professionals for contracting for indemnity for their sole negligence does not as matter of law prohibit the use of limitation of damages provisions in professional service contracts.
In 1998, a real estate developer, 1800 Ocotillo, undertook the development of a townhouse project in Phoenix that bordered the Arizona Canal. Developer hired an engineering-architectural firm, The WLB Group, to perform surveying, engineering and landscape architecture services on the project. Developer had its design-build contractor sign the contract with the engineering-architectural firm, which included a limitation of damages provision limiting its exposure to the amount of its fees. While the parties never specifically discussed this provision, the entire contract was incorporated into a supplemental contract between the Developer and the engineering architectural firm approximately two years later.

Argonaut Great Cent. Ins. Co. v. DiTocco Konstruction, Inc.
2007 U.S. Dist. LEXIS 93846 (D.N.J. Dec. 21, 2007)
After a fire destroyed a T.G.I. Friday’s restaurant and all of its equipment, the meaning of the subrogation continuation clause contained in the contract between the owner and the contractor who had performed renovations and remodeling of the restaurant five years earlier became the focal point of ensuing dispute.

Jalapenos, LLC v. GRC General Contractor, Inc.,
2007 PA Super 391, 2007 Pa. Super. LEXIS 4411 (Dec. 19, 2007)
Jalapenos, LLC, hired GRC General Contractor, Inc. to remodel a restaurant. The parties signed standard American Institute of Architects contracts (AIA Forms A101 and A201 – 1997). Under the contract, Jalapenos was required to obtain Builder’s Risk “all-risk” property insurance or equivalent, or inform the contractor in writing before the work began if it did not intend to purchase such insurance. Furthermore, if GRC was damaged by Jalapenos’ failure to maintain the required insurance without notifying GRC, then Jalapenos would be liable for all reasonable costs attributable to such failure.

Steel Services Corp. v. Board of County Commissioners
2007 U.S. App. Lexis 30052 (6th Cir. Dec. 27, 2007)
The Cincinnati Reds were building a new baseball stadium. Hamilton County (“County”) awarded Contractor, Steel Service Corp. (“Contractor”), a $33 million dollar contract for the fabrication and erection of the steel superstructure. The start of the Contractor’s work was delayed. The County’s construction manager directed the Contractor to accelerate its work due to the project delays and take extraordinary measures to comply with the contract and schedule. Contractor accelerated and submitted a claim for additional costs incurred by itself and its subcontractors. The County and Contractor executed a change order providing for a provisional payment to be applied against the amount, if any, to which the Contractor was ultimately determined to be entitled in reimbursement of the acceleration costs. Neither party accepted responsibility for the delays in the change order. The change order stated that Contractor had begun implementing extraordinary measure, had incurred additional costs and would continue to do so throughout the course of the project. Construction proceeded.

U.S. ex rel. Platinum Mechanical, LLC v. U.S. Surety. Co.
07 Cv. 3318(CLB), 2007 U.S. Dist. LEXIS 94026( S.D.N.Y. Dec. 21, 2007)
CFP Group, Inc. was awarded a contract with the United States Government to refurbish facilities at Stewart Air National Guard Base in New York. Platinum Mechanical, LLC subcontracted to perform all of the plumbing and HVAC work for the Project. All work on the Project was to be completed by March 12, 2007. Notice to proceed issued on June 14, 2006.

Tennessee Gas Pipeline Co. v. Technip USA Corp.
2007 Tex. App. LEXIS 9951, No. 01-06-00535-CV (Tex. App. Dec. 21, 2007)
The Court of Appeals of Texas for the First District was asked to review a trial court’s limitation of a jury award for damages to only those damages associated with defective work. In making its ruling, the Court of Appeals was asked to assess the extent of a waiver of consequential damages clause and which damages were considered consequential barred by said clause. After overlapping contract provisions and the damages sought, the Court of Appeals found that damages flowing from delay were recoverable so long as they were direct, meaning that they flowed naturally and necessarily from the delay.

United States Fire Insurance Co. v. J.S.U.B., Inc. and Auto-Owners Insurance Co. v. Pozzi Window Co.
2007 Fla. LEXIS 2394 and 2007 Fla. LEXIS 2391 (Dec. 20, 2007)
On December 20, 2007, the Florida Supreme Court decided United States Fire Insurance Company, et al. v. J.S.U.B., Inc., et al., 2007 Fla. LEXIS 2394, and Auto-Owners Insurance Company v. Pozzi Window Company, et al., 2007 Fla. LEXIS 2391 – two cases dealing with whether a standard form CGL policy with products completed operations hazard coverage issued to a general contractor, cover a general contractor’s liability to a third party for repair and/or replacement costs due to defective work by its subcontractor.

La Liberte, LLC v. Keating Building Corp. v. Roman Mosaic and Tile Co.
Civ. A. No. 07-1397, 2007 U.S. Dist. LEXIS 90878 (E.D. Pa., Dec. 11, 2007)
The United States District Court for the Eastern District of Pennsylvania dismissed the third-party complaint of the defendant holding that the statute of limitations had expired on the defendant’s performance bond claims against surety companies.
Plaintiff La Liberte LLC sued Defendant Keating Building Corporation for breach of contract, breach of implied warranty, and breach of express warranty in connection with the work Keating performed on a hotel owned by La Liberte. Under the contract between La Liberte and Keating, Keating was to make renovations and construct an addition to La Liberte’s hotel. Keating, in turn, entered into several subcontracts. Among them, Keating contracted with Voegele Mechanical Inc. and Shannon Plastering and Drywall Corporation. Both subcontracts contained warranty provisions which ran one year from acceptance by La Liberte. Voegele and Shannon obtained performance bonds for the benefit of Keating. The performance bonds contained the following identical provisions:

C&I Steel, LLC v. Travelers Casualty & Surety Co.
70 Mass. App. Ct. 653, 2007 Mass. App. LEXIS (App. Ct. Nov. 6, 2007)
The town of Westford awarded Peabody Construction Company, Inc. (“Peabody”) a contract for construction of a middle school. The project required a payment bond which Peabody obtained from Travelers Casualty and Surety Company (“Travelers”) for the full value of the contract. Peabody, as principal, and Travelers, as surety, jointly and severally bound themselves “to [Westford] to pay for labor, materials and equipment furnished for use in the performance of the [c]onstruction [c]ontract.” The bond set forth that the construction contract incorporated the agreement between Westford and Peabody, including all the contract documents and changes thereto.