Bell BCI Co. v. United States
570 F.3d 1337 (Fed. Cir. Jun. 25, 2009)

Plaintiff, Bell BCI Company (Bell), a general contractor, sued the United States (the “Government”) for damages plus interest under the Contract Disputes Act for the unpaid balance of the contract price, unresolved change order claims, delay damages, labor inefficiency costs and profit thereon. Bell also asserted claims on behalf of five subcontractors.

Addicks Services, Inc., Appellant v. GGP-Bridgeland, LP
2010 U.S. App. LEXIS 2623 (5th Cir. Feb. 8, 2010)

Plaintiff, Addicks Services, Inc. (“Addicks”) sought damages for extra work and delay costs incurred while performing land improvement work for a residential development in Texas. Addicks’ claims were denied by the district court because Addicks executed monthly waivers and releases to receive progress payments which waived their claims for extra work and delay costs.

Goldsmith Assoc., Inc. v. Del Frisco’s of Philadelphia, Inc.
2009 U.S. Dist. LEXIS 92193 (E.D. Pa. Oct. 1, 2009)

Grasso Holding Acquisition, Inc. (“Grasso”) entered into a lease with Del-Frisco’s of Philadelphia (“Del-Frisco’s”) to occupy and renovate the bottom floors of the Packard Building in Philadelphia, PA for use as a restaurant. Building owners, Chest-Pac Associates, Inc. (“Chest-Pac”) and Grasso, reserved the right to review and approve the designs for the renovation. Once the lease expired, the renovation improvements were to become the sole property of Chest-Pac and Grasso. After negotiating the lease, Del-Frisco’s contracted with Lorient, LLC to serve as the general contractor for the renovations. Lorient then subcontracted with Plaintiff, Goldsmith Associates, Inc. (“Goldsmith”) to provide the electrical work. Goldsmith submitted invoices in the amount of $1,835,110.87 but was allegedly only paid $734,879.30. Goldsmith commenced an action against Del Frisco’s, Chest-Pac and Grasso, asserting a claim of unjust enrichment, and seeking to recover $1,100,231.57 in unpaid work. The defendants moved to dismiss the Complaint as legally insufficient.

Fortney & Weygandt, Inc. v. American Manufacturers Mutual Insurance Co.
2010 U.S. App. Lexis 2836 (6th Cir. Feb. 12, 2010)

The United States Court of Appeals for the Sixth Circuit recently held that where a contractor’s defective foundation work required complete demolition and rebuilding of project that the defective work exclusion of commercial general liability policy did not preclude coverage for destruction of portions of the building not defectively constructed.

A.A. Bellucci Constr. Co. v. United States Surety Co.
2010 U.S. Dist. LEXIS 8369 (M.D. Pa., Feb. 2, 2010)

CSI Engineering, DC, P.C. (“CSI”) entered into a contract with a division of the U.S. Department of Labor to act as the general contractor for one of its construction projects. In turn, CSI subcontracted a portion of the work to A.A. Bellucci (“Bellucci”). The contract between CSI and Bellucci required mediation and arbitration to resolve disputes between them. To secure payment to all of its subcontractors, including Bellucci, CSI furnished Miller Act payment bonds from United States Surety Company (“Surety”) and U.S. Specialty Insurance Company (“Speciality”).

Hunt Construction Group, Inc. v. National Wrecking Corporation
587 F.3d 1119; 2009 U.S. App. LEXIS 25909 (2009)

Plaintiff, Hunt Construction Group (“Hunt”), commenced an action against one of its subcontractors, National Wrecking Corporation (“National”) and against two sureties (the “Sureties”) on National’s performance bond. The Sureties argued that Hunt failed to give timely notice of default depriving the Sureties of a realistic opportunity to exercise their rights under the bond to cure National’s defective performance.

GTECH Corp. v. Commonwealth, Dept. of Revenue
965 A.2d 1276 (Pa. Commw. 2009)

The Commonwealth Court of Pennsylvania considered whether the Pennsylvania Procurement Code provides the exclusive remedy for aggrieved bidders to challenge the procedure and outcome of bidding contests in the context of a procurement for the Pennsylvania Lottery. The Court found that while the Procurement Code provides an exclusive remedy for substantive challenges (i.e., a general right of protest to an offeror who is aggrieved in connection with the solicitation or award of a contract), it did not provide a remedy for procedural challenges.

U.S. for Use and Benefit of Greenmoor, Inc. v. Travelers Casualty and Surety Co.
2009 U.S. Dist. LEXIS 113153 (W.D. PA 12/04/2009)

The Court held that a properly terminated subcontractor was nevertheless entitled to payment for contract work and extras performed prior to termination, less certain offsets for contractor’s damages. Subcontractor was also entitled to interest at 1% per month under a prompt payment statute, but because it was properly terminated was not entitled to lost profit on the terminated portion of the subcontract.

Charter Foods Inc. v. Derek Engineering of Ohio, Inc.
2009 U.S. App. LEXIS 115477 (E.D. KY. Dec. 11, 2009)

The District Court for the Eastern District of Kentucky held that a general contractor, who had performed excavation work on a site in accordance with the plans and specifications, could not be held liable for breach of contract as a matter of law, but could potentially be held liable to the owner for negligence if the contractor breached the duty of care it owed the owner.

U.S. ex rel Pioneer Construction v. Pride Enterprises
2009 U.S. Dist. LEXIS 110935 (M.D. Pa., November 27, 2009)

The court denied the contractor’s claim for summary judgment, which was based on the theory that the subcontractor’s claims were barred by the releases it submitted with partial payment requests, holding that the contractor’s submission of the subcontractor’s claims to the government as part of an equitable adjustment request supported an inference that the parties by course of performance did not regard the releases as barring the claims. Further, the court held that notwithstanding Pennsylvania law to the contrary, federal law allows recovery of delay costs under a Miller Act payment bond.