Balfour Beatty Infrastructure, Inc. v. Mayor and City Council of Baltimore, 2017 U.S. App. Lexis 7252 (4th Cir., April 25, 2017)

The United States Court of Appeals for the Fourth Circuit recently addressed whether the City of Baltimore (the “City”) had abandoned a contractually required administrative dispute resolution process and relieved Balfour Beatty Infrastructure, Inc. (the “Contractor”) of any obligation to use the administrative dispute resolution process before seeking judicial review of the Contractor’s claims.

The City and the Contractor entered into two contracts (the “Contracts”) whereby the Contractor agreed to build certain parts of a wastewater treatment plant servicing the Chesapeake Bay. The Contracts stipulated that time was of the essence and permitted the City to assess liquidated damages if the Contractor failed to meet the specified completion date.  The Contracts also incorporated by reference the administrative dispute resolution process set forth in the City’s “Department of Public Works Specifications – Materials, Highways, Bridges, Utilities and Incidental Structures 2006,” known as the “Green Book,” which requires contractors engaged by the City in connection with public works projects to seek administrative review by the City’s Department of Public Works of any dispute related to their contracts before suing in court.

Allied World Specialty Ins. Co. v. Abat Lerew Constr., 2017 U.S. Dist. LEXIS 61794 (D. Neb. Apr. 24, 2017)

 Abat Lerew Construction (“ALC”) entered into multiple construction projects which required it to obtain surety bonds guaranteeing its performance. ALC obtained the bonds from Allied World Specialty Insurance Company (“Allied”) and also entered into an indemnity agreement with Allied.  In that agreement ALC agreed to indemnify and hold Allied harmless from and against all liability and to deposit with Allied collateral in an amount determined by Allied to be sufficient to cover liability for any claims under the bonds.

During ALC’s performance of the bonded contracts, Allied received claims on the bonds in excess of $300,000. Invoking the terms of its indemnity agreement with ALC, Allied demanded that ALC post collateral security in the amount of $400,000 to cover liability for the claims.  ALC refused and Allied commenced an action seeking equitable relief requiring ALC to deposit the demanded collateral security.  Upon commencement of the litigation, Allied asked the court to issue a preliminary injunction requiring ALC to post the $400,000 security and restraining ALC from transferring assets.

Alkemade v. Quanta Indem. Co., 2017 U.S. App. LEXIS 6896 (9th Cir. Apr. 20, 2017)

 In 1994, Adrianus and Rachelle Alkemade (the “Alkemades”) bought a house from Meltebeke Built Paradise Homes (“Meltebeke”). The home was built on expanding soils, causing significant structural damage.  Meltebeke repaired the existing damage and hired an engineering firm to install a helical pier foundation, which would have prevented any further damage to the home.  However, the helical pier foundation was also installed negligently, afflicting the home with the same type of structural damage as before.

Alkemades sued Meltebeke for negligent supervision of the helical piers installation. Meltebeke entered a settlement agreement with Alkemades in which Meltebeke assigned to Alkemades the right to sue its insurers, Quanta and GFIC, who refused to defend Meltebeke on grounds that its knowledge of the damage caused by the original, defective construction prevented coverage under a known damages provision in Meltebeke’s policies (the “Policies”).  Alkemades subsequently sued the issuers for breach of contract in the U.S. District Court for the District of Oregon for their failure to defend and indemnify Meltebeke.  The insurers moved for summary judgment.

The Policies excluded coverage for damage known by the insured, in whole or in part, that occurred before the policy period began. If such damage was known to the insured, then any “any continuation, change or resumption” of that damage was also deemed known, and excluded.

Nova Contr., Inc. v. City of Olympia, No. 48644-0-II, 2017 Wash. App. LEXIS 913 (Ct. App. Apr. 18, 2017)

This case arose out of a public project in which the City of Olympia (“City”) hired Nova Contracting, Inc. (“Nova”) to replace a culvert. A prior City project on which Nova completed work ended with Nova receiving extra compensation due to the City’s design errors and, as a result, a grudge held by some City staff against Nova.  The present contract required Nova to send submittals describing its plans for bypass pumping and excavation to the City’s engineer for approval before it could begin work.  The City’s decision regarding submittals was final and Nova bore the risk and cost of delay due to any non-approval.
The City issued its Notice to Proceed on August 11, 2014, but Nova could not begin construction due to the City’s rejection of its submittals. Nearly one month later, the City declared Nova to be in default because it failed to provide satisfactory submittals and failed to mobilize to the site.  Coincidentally, that same day, Nova had mobilized to the site; the City, however, later ordered Nova to cease work because it had commenced operations before obtaining the requisite approval.  Nova protested the City’s declaration of default, but the City terminated the contract on September 24.

Nova filed suit against the City for breach of contract, claiming that its handling of the submittals imposed requirements that were not part of the project’s specifications, thereby delaying Nova’s performance to a point where the project could not be timely completed. In support thereof, Nova’s witnesses declared that the City had appeared to be reviewing the submittals with the goal of rejecting them as a sort of “gotcha” review employed to prevent Nova’s performance.  The City moved for summary judgment, and the trial court granted its motion.  Nova appealed, arguing that there existed genuine issues of fact as to why the project was not completed and that the City had breached its duty of good faith by preventing Nova from attaining its justified contractual expectations.  The City argued that the duty of good faith did not apply because it had unconditional authority to accept or reject Nova’s submittals.

Melchert v. Pro Elec. Contrs., 2017 Wis. Lexis 169 (April 7, 2017)

The Wisconsin Department of Transportation (“DOT”) contracted with Payne & Dolan (“P&D”) as General Contractor on a road improvement project. P&D in turn contracted with Pro Electric Contractors (“Pro Electric”) to install concrete bases for new traffic signal poles.  DOT provided Pro Electric with detailed plans and specifications for the project (“Project Plan”) that specified the location of the concrete bases and the excavation equipment to be used.  Pro Electric was required to comply with the Project Plan and could only make deviations if approved by DOT’s engineer.

While excavating one of the specified locations, Pro Electric unknowingly severed a sewer line, causing sewage backup and flooding on adjoining private property. Pro Electric then backfilled the excavation site without inspecting the sewer line for damage.  The private property owners (“Owners”) brought a negligence action against Pro Electric.  The trial court granted summary judgment in favor of Pro Electric, ruling that it was immune from liability because it was merely implementing DOT’s design decisions.  The court of appeals affirmed, and Owners appealed to the Supreme Court of Wisconsin.

Archon Construction Co. v. U.S. Shelter, LLC, 2017 Ill. App. LEXIS 197 (March 31, 2017)

U.S. Shelter, LLC, a developer, undertook to develop a new residential subdivision in Elgin, Illinois. As part of that project, U.S. Shelter retained Archon Construction Company, Inc. (“Archon”) to install the sanitary sewer system for $890,955.29.

Archon’s contract provided that after the system was completed, Archon would videotape the interior of the piping, to allow the City of Elgin (“City”) to inspect and determine the acceptability of the system as installed.

Archon completed its work in August of 2005. In early 2007, the City requested that Archon perform the required videotaping.  Archon complied.

After viewing the videotapes, the City announced that the system, as installed, was not acceptable and that certain repairs were necessary. In particular, the City specified that one of the lines running through the system needed to be replaced because of cracking, the existence of gravel in the lines, and other issues.  While the entire sewer system had been constructed with PVC pipe, the City directed that this line be replaced with ductile iron pipe.

In re: Linear Electric Co., Inc., No. 16-1477, 2017 U.S. App. Lexis 5527 (3d Cir., March 30, 2017)

This case concerns whether suppliers, Cooper Electrical Supply Co. and Samson Electrical Supply Co. (“Suppliers”), could file construction liens under New Jersey law, despite the fact that Linear Electric Inc. (“Contractor”), filed a petition for bankruptcy, which automatically stays any act to create or perfect any lien against the contractor’s property. Two weeks after Contractor filed for bankruptcy, the Suppliers filed construction liens against projects in New Jersey where the materials were incorporated.  Following a motion by the Contractor, the Bankruptcy Court held that the liens were in violation of the automatic stay provision of the Bankruptcy Code. The District Court affirmed the Bankruptcy Court’s holding that, under New Jersey law, the liens were claims against the Contractor’s accounts receivables, which receivables are part of the bankruptcy estate and protected by the automatic stay.  On appeal, the Third Circuit affirmed the ruling of the District Court.

Central Ceilings, Inc. v. Suffolk Constr. Co., Inc., 2017 Mass App. Lexis 36 (March 29, 2017)

 The Massachusetts State College Building Authority contracted with Suffolk Construction Company (“Suffolk”) to serve as the general contractor for the construction of dormitories at Westfield State University (“the Project”). Suffolk subcontracted with Central Ceilings, Inc. (“Central”) to install interior and exterior framing, drywall, and door frames for the Project.

Central’s work was impeded by Suffolk’s failure to: coordinate the work of other trades; establish proper elevation, column, and control lines; timely and properly coordinate delivery of the door frames; and ensure that the buildings were weather-tight and properly heated. Its workers were forced to repeatedly demobilize from one area and remobilize in another, and to work in the same space and at the same time as other subcontractors, i.e. stacking of trades.  Central’s project manager and other supervisors were forced to coordinate and administrate the remobilizations.  Both the remobilizations and the stacking of trades significantly increased Central’s labor costs.

KICC –Alcan Gen. v. Crum & Forster Specialty Ins. Co., 2017 U.S. Dist. LEXIS 37560 (March 16, 2017)

A Contractor/Construction Manager, KICC-Alcan General (“KICC”), entered into a subcontract with an MEP subcontractor, Superior Group (“Superior”), concerning the construction of two buildings at an airforce base in Alaska. Superior sued KICC for approximately $2 million in costs it incurred in excess of the contract value, allegedly caused by KICC’s failure to properly manage the project.  KICC tendered Superior’s claims to its Errors and Omissions insurance carrier, Crum & Forster Specialty Insurance Company (“C&F”).  C&F denied both defense and indemnity of Superior’s claims.  KICC settled its claims with Superior prior to trial.  KICC then sued C&F for its breach of the duty to defend and indemnify against Superior’s claims, as well as a breach of its duty of good faith.

The terms of KICC’s E&O policy provided coverage for “damages… because of… an act error or omission in the rendering or failure to render professional services by any insured.”  The contract defined “professional services” as “those functions performed for others by you or by others on your behalf that are related to your practice as a consultant, engineer, architect, surveyor, laboratory or construction manager.”

Superior alleged that KICC: mismanaged a soil contamination issue at the beginning of the project; failed to provide timely responses to requests for information and contract modifications; and directed other subcontractors to work in the same areas at the same time as Superior, resulting in delays and added costs to Superior on the project. Superior submitted a request for equitable adjustment (“REA”) for these costs and delays, but KICC denied the REA.  In its lawsuit, Superior asserted claims for breach of contract and quantum meruit.

Broomfield Senior Living Owner, LLC v. R.G. Brinkmann Co., 2017 Colo. App. Lexis 261 (March 9, 2017)

R.G. Brinkmann Company, as general contractor, was retained by Sunrise Development, Inc., a major national developer, for the construction of a senior assisted and independent living facility in Broomfield, Colorado. The project was owned by Broomfield Senior Living Owner, LLC.

Section 13.7 of the contract between Brinkmann and Sunrise provided that all claims arising from defects in Brinkmann’s work would be deemed to accrue no later than final completion of the project. On May 15, 2009, the project achieved final completion when a certificate of occupancy was issued.  No defects in the project were noted at that time.  In the Fall of 2012, however, Broomfield discovered broken sewer pipes at the project.  Further investigation revealed a number of defects that Broomfield attributed to Brinkmann’s poor construction.

On July 21, 2014, Broomfield filed a lawsuit asserting various defective workmanship claims against Brinkmann. Brinkmann responded by moving for summary judgment, arguing that under Section 13.7 of its contract with Sunrise, all defective work claims accrued no later than final completion on May 15, 2009 and that Colorado’s two year statute of limitations for civil claims therefore expired on May 15, 2011.  The trial court granted Brinkmann’s motion and dismissed Broomfield’s claims.