Addison Ins. Co. v. 4000 Island Blvd. Condo. Ass’n, 2017 U.S. App. LEXIS 26870 (11th Cir. Dec. 28, 2017)

The owner of a high-rise condominium building in Florida hired a contractor to replace the building’s concrete balcony railings with new railings featuring aluminum and glass.  The contractor on the project, Poma Construction (“Poma”), entered into a subcontract with Windsor Metal Specialties (“Windsor”), under which Windsor agreed to paint the new aluminum railings.

Two years after the work was completed, the owner sued Poma and Windsor in Florida state court, alleging that the railings were defective and required replacement.  In addition to replacing the railing system, the owner alleged that Windsor’s defective paint finish damaged other surrounding property, including railing post pockets and the concrete balcony slabs.

Windsor submitted the claim to its liability carrier, Addison Insurance Company (“Addison”).  Addison then filed a declaratory judgment action in the United States District Court for the Southern District of Florida, seeking a declaration that it had no duty to defend Windsor in the owner’s underlying lawsuit.  Windsor’s policy provided a defense against claims alleging that an “occurrence” caused “property damage.”  But the policy excluded claims alleging damage to Windsor’s own work product or to the particular part of a property on which Windsor performed its work.  Addison had invoked that exclusion, arguing that the owner merely alleged damage to Windsor’s own work and/or the part of the property on which Windsor performed its work, i.e. the balcony.  The District Court granted summary judgment in favor of Windsor, and Addison appealed.

Superior Steel, Inv. v. Ascent at Roebling’s Bridge, LLC, 2017 Ky. LEXIS 511 (December 14, 2017)

Corporex Development and Construction Management, LLC (“Corporex”), a design builder, contracted with Dugan & Meyers Construction Company (“D&M”), a construction manager and general contractor on the Ascent at Roebling’s Bridge (the “Project”), a 21-floor luxury condominium in Covington, Kentucky.
As a cost saving measure, D&M asked Superior Steel, Inc. (“Superior”) to fabricate the steel and to have Ben Hur Construction Company (“Ben Hur”) complete the erection and installation work.  Superior and D&M entered into a fixed price contract for $1,814,000.  In turn, Superior subcontracted with Ben Hur to erect the steel and metal decking for $444,000.  As structured, the payments would flow from Corporex to D&M to Superior.  Superior would then pay Ben Hur.

Lathan Co. v. State, No. 2016-CA-0913, 2017 La. App. LEXIS 2277 (La. App. 1st Cir. Dec. 6, 2017)

 
On December 6, 2017, the Louisiana Court of Appeals, First Circuit, reversed and remanded the trial court’s decision to grant the appellee’s, Jacobs Project Management Co./CRSS Consortium (“Jacobs”), motion for summary judgment.  In its opinion, the court of appeals held that a project manager owed a general contractor a duty of professional care and thus, could be held liable to a general contractor under Louisiana law, even if the project manager was not in direct privity with the general contractor.

On August 13, 2010, the appellant, The Lathan Company, Inc. (“Lathan”), entered into a public works contract with the State of Louisiana, Department of Education, Recovery School District (“Owner”) to renovate the William Frantz School in New Orleans.  Jacobs, through its contract with the Owner, served as project manager on behalf of the Owner.  Four years later, in August 2014, after filing an original lawsuit against the Owner in 2012 for payment of undisputed amounts due, Lathan filed an amended pleading that alleged inter alia Lathan was entitled to damages from Jacobs under general tort law for negligent professional undertaking and under Louisiana’s Unfair Trade Practices Act.  According to Lathan, Jacobs owed Lathan a duty of conduct in accordance with a standard of care similar to professionals in the industry and that Jacobs breached its duty of care by failing to (i) disclose mold conditions and the existence of an underground fuel tank at the outset of the project; (ii) timely respond to Lathan’s 400+ requests for information; (iii) perform inspections consistent with industry standards; and (iv) review, certify, and/or approve amounts due to Lathan.

S. Indus. Contractors, LLC v. Neel-Schaffer, Inc., No. 1:17CV255-LG-JCG, 2017 U.S. Dist. LEXIS 196804 (S.D. Miss. Nov. 30, 2017)

This case arises out of the West Pier Facilities project at the Port of Gulfport, Mississippi (“Project”).  Southern Industrial Contractors, LLC (“SIC”), the Project’s general contractor, filed suit for negligence against CH2M, the Project’s program manager and consultant, to recover increased costs incurred while excavating and working around underground debris at the Project site.  SIC alleged first that CH2M owed it a duty to ensure that the Project plans, specifications and bidding documents accurately represented the Project’s conditions, and second that CH2M breached this duty by failing to warn SIC of the underground obstructions it had encountered.  SIC argued that, as a result of CH2M’s breach, the Project became much more expensive and time-consuming.  CH2M filed a motion to dismiss the complaint, arguing it owed no duty to SIC.

The court first recognized that Mississippi law imposes upon design professionals, such as architects and engineers, a duty to exercise ordinary skill and diligence, and further, that Mississippi law allows third parties to rely upon the contractual obligations that a design professional owes to a project’s owner.  The court explained that, because of the design professional’s contractual obligations to the owner, the design professional owes a further duty, sounding in tort, to a contractor who relies upon the design to his economic detriment.  The court recognized that whether the design professional owes such a duty to a contractor is a factual determination that must be made on a case-by-case basis.

Pritchett Controls, Inc. v. Hartford Accident & Indemnity Co., 2017 U.S. Dist. LEXIS 192182, 2017 WL 5591872 (D. Md. Nov. 21, 2017)

James W. Ancel, Inc. (“JWA”) was the prime contractor on a project for the Maryland Transit Authority in Baltimore.  JWA subcontracted a portion of the work to Pritchett Controls, Inc. (“Pritchett”).  The subcontract contained a forum selection clause requiring any disputes to be “brought in the District or County where Contractor’s  principal office is located….”  JWA’s principal office is located in Towson, Maryland, which sits in Baltimore County.

As required by Maryland’s Little Miller Act, JWA, as principal, executed a payment bond with Hartford Accident & Indemnity Co. (“Hartford”), as surety.  This case involves Pritchett’s claim against Hartford for payment under the bond.

While performing its work on the project, Pritchett submitted twelve (12) payment applications to JWA totaling $744,799.  It completed its work on March 16, 2017 but never received any payment for its work.  On May 11, 2017, Pritchett submitted a notice of claim to Hartford.  When that claim remained unpaid by July 25, 2017, Pritchett filed this action against Hartford in the United States District Court for the District of Maryland.

Fulton County v. Soco Contracting Company, Inc., 2017 Ga. App. LEXIS 568 (Ga. Ct. App., November 15, 2017) 

Fulton County contracted with SOCO Construction Company (“SOCO”) to build a cultural center near the Fulton County Airport.  The contract specified that the contract sum and the contract time could only be changed according to County procedure, which required “a written, bilateral agreement (Modification) between the County … and the contractor.”

Adverse weather conditions, design delays, change order requests, and a federal government shutdown allegedly delayed the project.  Despite the County’s program manager listing more than 30 change orders in the project’s change order evaluation log, the County never issued any written change orders, including any change orders extending the contract time to account for the delays.  The County also withheld payment from SOCO.

SOCO sued the County for breach of contract and bad faith performance of contract, and it sought attorney fees and injunctive relief.

SWN Prod. Co., LLC v. Long, 2017 W. Va. LEXIS 892 (W. Va. Oct. 18, 2017)

Respondents Richard and Mary Long (“Respondents” or “Lessors”) brought a state court action against Petitioner SWN Production Company, LLC (“Petitioner” or “Lessee”) seeking to recover alleged payments owed pursuant to an oil and gas lease (the “Lease”) entered into between Petitioner and Respondent.
Petitioner filed a motion to compel arbitration, relying on the Lease’s arbitration provision, which reads:  “In the event of a disagreement between Lessor and Lessee concerning this Lease, performance thereunder, or damages caused by Lessee’s operations, the resolution of all such disputes shall be determined by arbitration in accordance with the rules of the American Arbitration Association.”

United States v. John C. Grimberg Co., Case No. 1:16-cv-991, 2017 U.S. Dist. LEXIS 173362 (E.D. Virginia, October 19, 2017)

John C. Grimberg (“Prime Contractor”) was awarded a contract (the “Prime Contract”) to design and complete certain improvements at the FBI Academy in Quantico, Virginia (the “Project”).  Hartford Accident and Indemnity Company (“Surety”) issued payment and performance bonds for the Project pursuant to the Miller Act.  The Prime Contractor thereafter entered into a subcontract (the “Subcontract”) with Kitchens-to-Go (“Subcontractor”) to furnish, install, lease and remove a temporary kitchen facility for the Project.  The Subcontract contained a “no-damages-for-delay” clause, which provided that the Prime Contractor shall not be liable for delays beyond its control and that the Subcontractor is “entitled only to reimbursement for damages for delay actually recovered from the Owner.”  The Subcontract also incorporated the dispute resolution procedures in the Prime Contract, which required that all “disputes arising out of Owner acts, omissions or responsibilities” be submitted through an administrative process with the government’s contracting officer under 41 U.S.C. §§7101 et. seq.

The Subcontract originally contemplated a Project duration of approximately 13 months, ending on April 5, 2014, but was ultimately extended until June 27, 2015.  The Subcontractor submitted its Application for Payment to the Prime Contractor, which included $607,221 for extended rental of the kitchen facilities.  Although the Prime Contractor submitted a payment request to US Department of the Navy (“Owner”), for the extended rental and use of Subcontractor’s temporary kitchen facilities, this request was rejected by the Owner.  The Prime Contractor refused to pay Subcontractor’s Application for Payment and the Subcontractor filed a complaint against the Surety under the Miller Act.

Team Contrs., L.L.C. v. Waypoint NOLA, L.L.C., No. 16-1131, 2017 U.S. Dist. LEXIS 162172 (E.D. La. Oct. 2, 2017).

Waypoint NOLA (“Waypoint”) was the owner of a hotel construction project in New Orleans (the “Project”).  Waypoint contracted with Team Contractors (“Team”) to serve as the Project general contractor and HC Architecture (“HCA”) to serve as the Project architect.  HCA, in turn, subcontracted with KLG to prepare the mechanical, electrical, and plumbing (“MEP”) plans.

HCA delivered a complete set of specifications, including KLG’s MEP plans, to Team, and Team began work.  It was later discovered that the MEP plans did not comply with code requirements.  Team was forced to remove and reconstruct the MEP work before proceeding with its work as scheduled.
Team filed suit for breach of contract against Waypoint and for negligence against Waypoint, HCA, and KLG.  Team alleged it experienced delay and incurred damages when it was forced to remove and reconstruct the MEP work.  Its damages included extended home office overhead related to the delay.  Team’s expert used the Eichleay formula to calculate these damages.

Zirkelbach Constr., Inc. v. DOWL, LLC, 2017 Mont. Lexis 591 (Mont., Sept. 26, 2017)

In interpreting a state statute which makes contractual limitations on a party’s liability unenforceable in certain instances, the Supreme Court of Montana recently upheld the validity of a contract provision in a professional services agreement between a general contractor and a designer in which the parties waived consequential damages against each other and limited the liability of the designer to $50,000.00.
Zirkelbach Constr., Inc. (“Zirkelbach”) and DOWL, LLC (“DOWL”) entered into a professional services agreement (the “Agreement”), whereby DOWL agreed to provide design work to Zirkelbach, a general contractor, for the construction of a FedEx Ground facility in Billings, Montana.  The original contract price was $122,967, but was adjusted to approximately $665,000 after the parties made several addenda to the Agreement to account for additional services.