U.S. ex rel Pioneer Construction v. Pride Enterprises
2009 U.S. Dist. LEXIS 110935 (M.D. Pa., November 27, 2009)

The court denied the contractor’s claim for summary judgment, which was based on the theory that the subcontractor’s claims were barred by the releases it submitted with partial payment requests, holding that the contractor’s submission of the subcontractor’s claims to the government as part of an equitable adjustment request supported an inference that the parties by course of performance did not regard the releases as barring the claims. Further, the court held that notwithstanding Pennsylvania law to the contrary, federal law allows recovery of delay costs under a Miller Act payment bond.