Inc. v. City of Coffeyville

Hutton Contacting Company, Inc. v. City of Coffeyville
2007 U.S. App. LEXIS 9914, (10th Cir., April 30, 2007)
Contractor contracted to construct power and fiber-optic lines for the City. Upon completion of the project, the City refused to pay the final balance of the contract price, claiming that it was entitled to the funds as liquidated damages because the project was not completed on time. The Contractor sued to obtain the unpaid contract balance. The trial court ordered the City to pay the Contractor the retainage due minus $85,000 in liquidated damages. On appeal, the United States Court of Appeals for the Tenth Circuit, applying Kansas law, considered: 1) whether the contract’s force-majeure clause excused the Contractor for delays caused by late deliveries from its pole supplier; 2) whether the contract’s liquidated-damages provision was enforceable; and 3) whether the contract’s liquidated damages provision allowed the District Court to apportion delays between the Contractor and the City.
Continue Reading Tenth Circuit Holds Supplier Delay Does Not Excuse Contractor Delay Under Force Majeure Clause; Holds Liquidated Damages Provision Allows For Apportionment Of Damages Where Owner Responsible for Some Delays