Rad and D’Aprile, Inc. v. Arnell Construction Corp, No. 502464/14, 2019 BL 131606 (NY. Sup. Ct. April 3, 2019)

In June of 2001, Arnell Construction Corp. (“Arnell”) entered into a prime contract to build two sanitation garages in Brooklyn for the New York City Department of Sanitation (the “City”).  Arnell subcontracted the project’s masonry work to Rad and D’Aprile, Inc. (“Rad”).  After execution of the subcontract, Rad was informed that the start of work would be delayed because the City had not yet obtained ownership or access to all portions of the site.  When its work did commence, only limited portions of the site were available.  This caused inefficiencies in Rad’s work and caused it to incur increased costs.Continue Reading New York Court Holds Contractor’s Failure to Timely Pass Through Subcontractor Delay Claim to the Owner Constitutes Breach of the Covenant of Good Faith and Fair Dealing

Whiting-Turner Contracting Co. v Guar. Co. of N. Am. USA, 2019 BL 97923 (Colo. App. Mar. 21, 2019).

This construction dispute involved rights and obligations under a performance bond supplied for an office building construction project in Denver, Colorado.  Whiting-Turner Contracting Company was the general contractor, and it subcontracted Klempco Construction to construct an anchor system for the project’s underground parking garage.  Klempco provided performance and payment bonds for the project from Guarantee Company of North America USA (“GCNA”).  When Klempco fell behind schedule, it stopped paying its sub-subcontractors and directed Whiting-Turner to assume responsibility for its work and sub-subcontractors.Continue Reading Colorado Court of Appeals Finds Contractor Satisfied Conditions Precedent Under Performance Bond

R&O Constr. Co. v. MBA Gen. Contracting, LLC, No. 1:18-cv-00042, 2019 BL 98680 (D. Utah Mar. 21, 2019)

On March 21, 2019, a Utah federal court granted Defendants MBA General Contracting, LLC and Cory Martin’s motion to dismiss R&O Construction Company’s claim for attorney fees.
R&O, as general contractor of a construction project, entered into two subcontracts with MBA to perform concrete work.  The first subcontract, entitled Master Subcontract Agreement, outlined general obligations between the parties.  The second, entitled Work Authorization Document, outlined more specific obligations.  R&O asserted various causes of action against MBA arising from MBA’s alleged breach of the subcontracts, including a claim for attorney fees.  MBA moved to dismiss the attorney fees claim, arguing that neither subcontract provides for such an award.Continue Reading Utah Federal Court Dismisses Claim for Attorney Fees Finding That Neither the Indemnification Provision nor the Failure-To-Perform Provision Applies to a Lawsuit Between Contractor and Subcontractor

Matter of Red Hook 160 LLC v. Borough Constr. Grp. LLC, No. 524909/18, 2019 BL 122210 (N.Y. Sup. Ct. Mar. 19, 2019)

This cases arises out of a project owner’s request for further itemization of amounts claimed in a construction manager’s mechanic’s lien.  Red Hook 160 LLC (“Red Hook”), the owner of the property sought to be liened, demanded a revised itemized statement of the mechanics’ lien filed by Borough Construction Group, LLC (“BCG”), the construction manager hired in connection with the construction and renovation of a six story building located at 160 Imlay Street in Kings County, New York.Continue Reading Supreme Court of New York Rejects Property Owner’s Request for Further Itemization of Mechanic’s Lien, Holding Production of Invoices Detailing the Quantity, Price and Date of Delivery of Materials Is Not Required