Contracts

Subscribe to Contracts via RSS

DuBaldo Electric, LLC v. Montagno Construction, Inc.
119 Conn. App. 423; 2010 Conn. App. LEXIS 55 (Conn. App. Feb. 23, 2010)

Subcontractor, DuBaldo Electric contracted with general contractor, Montagno Construction to perform electrical work in connection with the renovation of retail space leased by Burlington Coat Factory.
DuBaldo had estimated that it could complete the work in 3200 man hours over the scheduled ten week period. Issuance of the permit required for DuBaldo to commence its electrical work was delayed three weeks due to deficiencies in Burlington’s architectural design and understaffing at the City electrical inspector’s office. Unable to perform the electrical work without a permit, DuBaldo fell approximately three weeks behind. Nevertheless, Montagno refused to update the schedule. To make up for lost time, DuBaldo agreed to work 7 days a week with overtime. In addition, Montagno hired Globe Electric to work along side DuBaldo, and deducted from DuBaldo’s account the amount it paid to Globe for work performed within DuBaldo’s scope.

North Amer Spec Ins. Co. v. Ames Corp./Dawson Building Contractors, Inc. JV
2010 U.S. Dist. LEXIS 25748 (S.D. Fla. Mar. 10, 2010)

Defendant Ames Corporation/Dawson Building Contractors, Inc. (Ames/Dawson), as general contractor, engaged American Roofing, LLC (American Roofing) to perform roofing work at the Veterans Administration Medical Center located in West Palm Beach, Florida. Plaintiff North American Specialty Insurance Company (NAS), as surety, issued performance bonds on behalf of American Roofing, naming Ames/Dawson, as obligee.

Law Co. v. Mohawk Construction & Supply Co. Inc.
2010 U.S. Dist. LEXIS 24302 (D. Kan. March 16, 2010)

The United States District Court for the District of Kansas recently considered the enforceability of a no-damages-for-delay clause in a construction subcontract. After finding that the clause was enforceable, the Court rejected each of the exceptions urged by the subcontractor.

The matter before the District Court involved a series of contracts entered into with regard to the construction of a Cessna C-10 Citation Service Center in Wichita, Kansas (the “Project”). The project owner, Cessna Aircraft Company, retained plaintiff, The Law Company, Inc. (“Law”), to provide general construction services in connection with the Project. In turn, Law, entered into a series of subcontract agreements, including one with Mohawk Construction and Supply Company, Inc. (“Mohawk”). Mohawk’s subcontract contained a no-damages-for-delay provision, particularly providing that Mohawk’s sole remedy for delay was an extension of time.

Dew Electric, Inc. v. Mass Electric Construction Co.
2010 U.S. Dist. LEXIS 19904 (W.D.N.C. Mar. 5, 2010)

Defendant Mass-Aldridge, a Joint Venture, (“MAJV”) entered into two contracts with the Charlotte Area Transit System (“CATS”) to construct CATS’ new South Corridor Light Rail Project. Under the first contract, MAJV agreed to construct the Traction Power & Overland Catenary System and under the second contract, MAJV agreed to construct the Train Control & Communication system (collectively the “Prime Contracts”). In furtherance of its work under the Prime Contracts, MAJV entered into a subcontract for each project (collectively the “Subcontracts”) with Plaintiff Dew Electric, Inc. (“Dew”).

Flagstaff Affordable Housing LP v. Design Alliance, Inc.
223 P.3d 664, 2010 Ariz. LEXIS 11 (Ariz. Feb. 12, 2010)

In 1995, the Owner of a low income housing project, Flagstaff Affordable Housing Limited Partnership contracted with Design Alliance, Inc. (“Architect”) for the design of the Project. The design had to comply with the Federal Fair Housing Act’s (“FFHA”)accessibility guidelines. The Owner also contracted with Butte Construction Company (“Contractor”) for the construction of the apartments. The Project was completed in 1996.

Universal Concrete Products Corp. v. Turner Construction Co.
595 F.3d 527 (4th Cir. Feb. 19, 2010)

Universal Concrete Products Corp. (“Universal”) sued Turner Construction Co. (“Turner”) for breach of contract and several other claims seeking payment for $885,507 worth of precast concrete work Universal had completed at the Granby Tower construction project in Norfolk, Virginia (“Project”).

Universal had entered into a written subcontract with Turner for the installation of precast concrete at the Project. Turner had a prime contract with the project owner’s to provide general construction work on the Project. The Project fell through in March 2008 when the owner could no longer finance it. By that point, however, Universal had already substantially completed all of its work at the Project. Turner, however, had not paid Universal for any of the work performed because Turner had not yet been paid by the owner. When Universal sought payment from Turner for the work performed, Turner refused citing a pay-when-paid provision in the subcontract.

Nova Crete, Inc. v. City of Elizabeth
2010 N.J. Super. Unpub. LEXIS 101 (N.J. Super. Ct. App. Div. Jan. 15, 2010)

The Court held that the consent of surety submitted by Nova Crete, Inc. (“Nova Crete”) did not comply with the bid specifications provided by the City of Elizabeth because its issuance was conditioned on an event other than the award of the contract to Nova Crete, and it therefore did not comply with the applicable New Jersey statute. Furthermore, this defect was material and could not be waived or cured. As a result, Elizabeth properly determined that Nova Crete was not the lowest responsible bidder on the project.

American Manufacturers Mutual Insurance Co. v. Payton Lane Nursing Home, Inc.
2010 U.S. Dist. LEXIS 8537 (E.D.N.Y. Feb. 2, 2010)

The United States District Court for the Eastern District of New York (“EDNY”) recently considered whether a surety could maintain a breach of contract claim against a construction project owner’s architect based upon the architect’s alleged wrongful certification of payments occurring prior to the execution of a takeover agreement. In rendering its opinion, the EDNY concluded that expert opinions were not required where the claim sounded in contract, rather than in tort. The EDNY also found that summary judgment was defeated because there remained genuine issues of material fact as to the extent of the architect’s scope of construction phase services and whether the architect failed to satisfy its construction phase service obligations.

Bell BCI Co. v. United States
570 F.3d 1337 (Fed. Cir. Jun. 25, 2009)

Plaintiff, Bell BCI Company (Bell), a general contractor, sued the United States (the “Government”) for damages plus interest under the Contract Disputes Act for the unpaid balance of the contract price, unresolved change order claims, delay damages, labor inefficiency costs and profit thereon. Bell also asserted claims on behalf of five subcontractors.

Goldsmith Assoc., Inc. v. Del Frisco’s of Philadelphia, Inc.
2009 U.S. Dist. LEXIS 92193 (E.D. Pa. Oct. 1, 2009)

Grasso Holding Acquisition, Inc. (“Grasso”) entered into a lease with Del-Frisco’s of Philadelphia (“Del-Frisco’s”) to occupy and renovate the bottom floors of the Packard Building in Philadelphia, PA for use as a restaurant. Building owners, Chest-Pac Associates, Inc. (“Chest-Pac”) and Grasso, reserved the right to review and approve the designs for the renovation. Once the lease expired, the renovation improvements were to become the sole property of Chest-Pac and Grasso. After negotiating the lease, Del-Frisco’s contracted with Lorient, LLC to serve as the general contractor for the renovations. Lorient then subcontracted with Plaintiff, Goldsmith Associates, Inc. (“Goldsmith”) to provide the electrical work. Goldsmith submitted invoices in the amount of $1,835,110.87 but was allegedly only paid $734,879.30. Goldsmith commenced an action against Del Frisco’s, Chest-Pac and Grasso, asserting a claim of unjust enrichment, and seeking to recover $1,100,231.57 in unpaid work. The defendants moved to dismiss the Complaint as legally insufficient.